FAR 42.1305

(a) The contracting officer shall insert the clause at 52.242-14 , Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated. (b) (1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15 , Stop-Work Order, in solicitations and contracts for supplies, services, or research and development. (2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its AlternateI. (c) The contracting officer shall insert the clause at 52.242-17 , Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial products. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial products.

More parts